Victorian Consolidated Legislation
[Index]
[Table]
[Search]
[Notes]
[Noteup]
[Previous]
[Next]
[Download]
[Help]
Casino (Management Agreement) Act 1993 - SCHEDULE 1
AGREEMENT dated 20 September 1993 BETWEEN THE HONOURABLE HADDON STOREY QC MLC
the Minister of the Crown for the time being administering the
Casino Control Act, acting for and on behalf of the State of Victoria
("State") AND CROWN CASINO LTD. ACN 006 973 262 with its registered office at
Hudson Conway House, 311 Glenferrie Road, Malvern, Victoria ("Company").
RECITALS A. The Authority has power to grant a casino licence under the
provisions of the Casino Control Act. B. Under section 15 of the
Casino Control Act it is a condition precedent to the grant of a
casino licence that an agreement in writing be entered into between the
Minister for and on behalf of the State and the proposed casino operator
identifying the casino to be the subject of the casino licence and containing
any terms and conditions that the Minister thinks fit. C. The Company has made
application for a casino licence for the Melbourne Casino and pursuant to such
application has provided information and submissions, including the Melbourne
Casino Complex Development Proposals and the Temporary Casino Complex
Development Proposals, to the State and the Authority. D. The Authority has,
in accordance with sections 9 and 10 of the Casino Control Act, carried out
investigations and enquiries in relation to the Company and other persons
required to be investigated. E. Upon execution of this document the Authority
and the Company will enter into the Casino Agreement. F. Subject to the terms
and conditions of this document and the Casino Agreement, the Authority has
agreed to grant the Casino Licence to the Company. G. The Casino Licence will
enable the Company to operate a casino from temporary premises. H. The
Minister has authority to enter into this document on behalf of the State and
this document is made pursuant to section 15 of the Casino Control Act. I. The
State acknowledges that the establishment of the Melbourne Casino Complex is a
large scale development project requiring significant capital expenditure and
that it is necessary to provide to the Company certain assurances contained in
this document and other Transaction Documents to facilitate the financing of
the Melbourne Casino Complex. J. The Company acknowledges that the
establishment of the Melbourne Casino Complex and the Temporary Casino Complex
is a major project for the State and that the State is reliant upon timely
completion and operation of the Temporary Casino and the Melbourne Casino and
accordingly certain assurances are given by the Company in this document and
other Transaction Documents. K. Certain provisions of this document are not
effective unless and until this document has been ratified by Act of
Parliament (as contemplated by clause 3). AGREEMENT
1. Division into Parts This document is divided into Parts as follows: PART
1-PRELIMINARY PART 2-APPROVAL OF DEVELOPMENT PROPOSALS AND CASINO LOCATION
PART 3-DEVELOPMENT PART 4-PAYMENTS TO THE STATE PART 5-EXCLUSIVITY PART
6-TERMINATION PART 7-GENERAL PART 1-PRELIMINARY
2. Definitions In this document, unless the context otherwise requires or the
contrary intention appears, terms defined in the Casino Control Act have the
same meanings and the following terms have the meanings indicated if they
start with a capital letter: "Agent" means National Australia Bank Limited ACN
004 044 937 and any successor to it as agent under the Facility Agreement;
"Agreement Act" means the bill referred to in clause 3.2(a) when that bill is
passed and comes into operation as an Act of Parliament as contemplated by
that clause; "Assets and Rights" means all the present and future undertaking,
property, assets and rights of or held by the Company; "Associate" has the
same meaning as in sections 10 to 17 of the Corporations Law; "Authorisation"
includes a consent, approval, licence, permit, franchise, permission, filing,
registration, resolution, direction, declaration and exemption; "Authority"
means the Victorian Casino Control Authority; "Ancillary Facilities" means all
facilities ancillary to the Temporary Casino or the Melbourne Casino
identified in the Melbourne Casino Complex Development Proposals or the
Temporary Casino Complex Development Proposals (as the case may be) to be
constructed on or located within the Temporary Casino Site or the Site,
including an hotel, restaurant, retail, recreation, entertainment and
carparking facilities, residential and office accommodation, staff facilities,
staff carparking, coach storage facilities and open space areas; "Bank Bill"
means a Bill which has been accepted by a bank authorised under the
Banking Act 1959 to carrying on banking business in Australia; "Bank
Guarantees" means the guarantees or letters of credit to be provided by the
Company pursuant to clauses 18.1 and 22.9; "Bill" has the meaning given to the
expression "Bill of Exchange" in the Bills of Exchange Act 1909 (but does not
include a cheque) and any reference to the drawing, acceptance or other
dealing of or with a Bill has the relevant meaning set out in that Act; "Bill
Rate" means on any day the rate (expressed as a yield per annum) which is-
(a) the rate quoted as the average bill rate on the Reuters Monitor System
Page "BBSY" (or any page which replaces that page) by about 10.30 a.m.
(Melbourne time) on that day for Bank Bills having a tenor of one
month; or
(b) if no average bill rate is published for bills of that tenor in
accordance with paragraph (a), the bid rate quoted to the State by
Westpac Banking Corporation on that date for the purchase of Bank
Bills having a tenor of one month; "Business Day" means a day (other
than a Saturday or Sunday) on which banks (as defined in the
Banking Act 1959 (Commonwealth)) are generally open for business in
Melbourne; "Casino Agreement" means the agreement between the
Authority and the Company providing, among other things, for the grant
of the Casino Licence; "Casino Asset" means an asset or undertaking of
the Company which forms part of the Secured Property and which
consists of-
(a) the Casino Licence;
(b) the Melbourne Casino;
(c) the Temporary Casino;
(d) all gaming equipment used in the Melbourne Casino or the Temporary
Casino;
(e) all revenue derived from the Melbourne Casino or the Temporary Casino
(other than revenues which have been deposited or are standing to the
credit of the Debt Protection Account or the Debt Service Reserve
Account (each as defined in the Facility Agreement) in accordance with
the Facility Agreement and any Authorised Investments (as defined in
the Facility Agreement) from either of those Accounts (or the proceeds
of any such Authorised Investment)); and
(f) all other assets of the Company necessary for the operation of the
Melbourne Casino or the Temporary Casino; and a reference to the
"Casino Assets" includes any part of them; "Casino Control Act" means
the Casino Control Act 1991 (Victoria);
"Casino Licence" means a casino licence as defined in the Casino Control Act
in relation to the Temporary Casino and the Melbourne Casino in the form of
the licence set out in Schedule One to the Casino Agreement; "Casino
Supervision and Control Charge" means-
(a) for the period from the Licensing Date until 30 June 1994, $5 000 000;
and
(b) for each Financial Year from 1 July 1994 until 30 June 1997, $5 000
000; "Commissioning" means the checking, testing and acceptance of the
operational readiness of and the procedures for the various components
of the Melbourne Casino Complex or the Temporary Casino Complex as the
case may be (including all staff, facilities and equipment);
"Completion" means the completion of the construction, the Fit-Out and
the Commissioning of the Temporary Casino, the Temporary Casino
Complex, the Melbourne Casino or the Melbourne Casino Complex, as the
case may be, to a state of operational readiness which complies with
the Completion Standards, as determined pursuant to clause 15, and
"Complete" and "Completed" have corresponding meanings; "Completion
Date" means (subject in each case to clause 16)-
(a) in relation to the Temporary Casino, the day immediately following the
expiration of 34 weeks from the Licensing Date or such later date as
is agreed by the State's Nominated Representative;
(b) in relation to the Temporary Casino Complex, the day immediately
following the expiration of 34 weeks from the Licensing Date or such
later date as is agreed by the State's Nominated Representative;
(c) in relation to the Melbourne Casino, the day immediately following the
expiration of 143 weeks from the Licensing Date or such later date as
is agreed by the State's Nominated Representative; and
(d) in relation to the Melbourne Casino Complex, the day immediately
following the expiration of 143 weeks from the Licensing Date or such
later date as is agreed by the State's Nominated Representative;
"Completion Standards" means-
(a) for construction of the Melbourne Casino, the Melbourne Casino
Complex, the Temporary Casino or the Temporary Casino Complex when-
(i) a certificate of occupancy is issued by the responsible authority;
(ii) the Melbourne Casino, the Melbourne Casino Complex, the Temporary
Casino or the Temporary Casino Complex is fit for use by the Company;
(iii) the Fit-Out and Commissioning has been completed in accordance with
the requirements of this document; and
(iv) all other requirements under this document have been complied with;
and
(b) in respect of the Melbourne Casino or the Temporary Casino, when a
certificate is issued by the Authority pursuant to clause 20 of the
Casino Agreement; "Construction Agreement" means the proposed building
agreement between the Company and a proposed builder substantially in
the form of the draft agreement a copy of which has been signed on
behalf of the Authority and the Company for the purposes of
identification; "Contractor' s Deed" has the meaning ascribed to that
term in the Supplemental Development Agreement; "Control Acts" means
the Building Control Act 1981 and the Planning and Environment Act;
"Default Rate" means the rate set under the
Penalty Interest Rates Act 1983 (Victoria) as at the date of any
default;
"Deal with" means deal with property in any way (other than enter into an arm'
s length agreement to sell dependent for effect on the State's consent)
including, but not limited to, offer for sale, grant an option in respect of,
create or Dispose of a right in respect of, render or permit to be subject to
an Encumbrance, convert, deposit, compromise or allow a counterclaim or right
of set-off to arise in respect of; "Design and Construction Programme" means
the programme for the design, documentation, construction, Fit-ut,
Commissioning and Completion of the Temporary Casino Complex or the Melbourne
Casino Complex (as the case may be) set out in Schedule One, as amended from
time to time with the prior written approval of the State; "Development
Agreement" means the agreement dated 30 August 1993 between the Company and
Hudson Conway Management Limited ACN 006 742 294 providing for the
construction of the Temporary Casino Complex and the procuring of the
construction of the Melbourne Casino Complex; "Dispose of" means sell,
transfer, assign, alienate, surrender, dispose of, deposit, Lease, part with
possession of and enter into any agreement or arrangement to do or allow any
of these things; "Drawings" means the plans, designs and working drawings
relating to the Temporary Casino Complex or the Melbourne Casino Complex (as
the case may be) provided by the Company and described in Schedule Two;
"Encumbrance" means a mortgage, charge, pledge, lien, assignment,
hypothecation, retention of title (other than a retention of title in respect
of trading stock), or any other right (including, without limitation, under a
trust, agency, hire purchase, sale and repurchase, sale and leaseback or
flawed asset arrangement) of a creditor to have its claims satisfied prior to
other creditors with, or from the proceeds of or by recourse to any asset, and
includes any agreement, arrangement or document conferring such a right or
having substantially the same economic effect; "Extension Event" has the
meaning given in clause 16.8; "Facility Agreement" means the $300 000 000
multi-option facility agreement dated 30 August 1993 between the Company, the
Financiers and the Agent; "Finance Documents" means the Facility Agreement and
the Financiers' Securities; "Financial Year" means from 1 July to 30 June
(inclusive); "Financiers" means the National Australia Bank Limited, Australia
and New Zealand Banking Group Limited, Hongkong Bank of Australia Limited, R &
I Bank of Western Australia Limited and State Bank of New South Wales Limited
and their successors, assigns and substitutes; "Financiers' Securities" means
the following securities given to the Agent as agent for the Financiers-
(a) a first registered fixed and floating charge over the undertaking and
all the assets of the Company including a mortgage over the
Casino Licence;
(b) a mortgage of the Site Lease and a mortgage of the Temporary Casino
Leases; and
(c) each other security given to the Agent or the Financiers as security
for the liabilities of the Company under the Facility Agreement;
"Fit-Out" means the application of finishing material, gaming
equipment, furniture, fittings, furnishings and such other built-in
and loose items required to bring any part of the Temporary Casino
Complex or the Melbourne Casino Complex (as the case may be) to a
stage to enable Commissioning to take place; "Fixed and Floating
Charge" means the second registered fixed and floating charge of 30
August 1993 by the Company in favour of the Minister on behalf of the
State; "Force Majeure Event" means any explosion, earthquake, natural
disaster, Government Action, sabotage, act of a public enemy, war
(declared or undeclared) or revolution which causes or results in
delay in the performance by a party of any of its obligations under
this document where the event, circumstance, default or delay could
not have been prevented, overcome or remedied by the exercise by the
affected party of a standard of care and diligence consistent with
that of a prudent, experienced and competent person including but not
limited to the expenditure of all reasonable sums of money, but does
not include-
(a) fire or flood;
(b) lightning, storm, hurricane or other action of the elements;
(c) strikes, lockouts, industrial disputes, labour disputes, industrial
difficulties, labour difficulties, work bans, blockages, picketing
action, secondary boycotts or any other labour action or lack of
action except those caused by Government Action;
(d) action or inaction by a court, government or authority, including
denial, refusal or failure to grant any permit, authorisation,
licence, approval or acknowledgement other than Government Action;
(e) mechanical, electrical or equipment breakdown or failure; or
(f) riot, civil commotion or blockade; "Founding Shareholders Agreement"
means the agreement dated 30 August 1993 between each Sponsor, Carlton
and United Breweries Limited ACN 004 056 106 and the Company providing
for the subscription for Shares by the Sponsors and Carlton and United
Breweries Limited; "Further Amendment Act" means the bill referred to
in clause 3.2(b) when that bill is passed and comes into operation as
an Act of Parliament as contemplated by that clause; "Government
Action" means-
(a) any breach by the State or the Authority of any obligation or duty
arising under the Casino Control Act or any Transaction Document;
(b) any negligent act or omission or any default or delay by a Government
Authority in the exercise of its rights, powers, privileges or
discretions conferred on it by law directly in connection with any
matter arising under the Casino Control Act or any Transaction
Document; or
(c) any combination of any of the activities in each of (a) or (b) above;
other than any of the activities described in (a) to (c) above in this
definition which occur in circumstances where the State or Government
Authority, as the case may be, acts in good faith-
(i) in satisfying a conflicting obligation or duty arising under the
Casino Control Act or any Transaction Document;
(ii) in exercising a conflicting right, power, privilege or discretion
conferred on it by law; or
(iii) in pursuing a matter which is in the public interest; and for the
purposes of this definition of "Government Action" "delay by a
Government Authority" means a delay by a Government Authority which,
having regard to the workloads and usual practices and procedures of
that Government Authority, would be considered extraordinary;
"Government Authority" means-
(a) the Parliament of the State;
(b) the Governor of the State whether or not acting in Council;
(c) any minister of the State (including the Minister), department or
official administering power or authority (other than judicial or
quasi judicial power) under any State law which regulates any of the
matters contemplated in any Transaction Document;
(d) the relevant authority under the Local Government Act 1989 having
jurisdiction over the Site or the Temporary Casino Site; "Gross Gaming
Revenue" means the total of all sums, including cheques and other
negotiable instruments whether collected or not, received in any
period by the Company from the conduct or playing of games within the
Temporary Casino or the Melbourne Casino (as the case may be) less the
total of all sums paid out as winnings during that period in respect
of such conduct or playing of games; "Lease" means an agreement or
arrangement under which property is or may be used, occupied,
retained, operated or managed by a person for consideration (of
whatever form) including, but not limited to, a lease, licence,
charter, hire purchase or hiring arrangement; "Licensing Date" means
the date which is 2 Business Days after the conditions precedent in
clause 5.1 are satisfied; "Licensing Payment Amounts" means the
amounts payable by the Company under clause 21.1; "Master Security
Agreement" means the agreement between the State, the Authority, the
Company, the Agent and the Sponsors relating, among other things, to
the priority of the Financiers' Securities and the Fixed and Floating
Charge; "Melbourne Casino" means those areas identified in the
Drawings of the Melbourne Casino Complex as the areas which constitute
a casino and includes the areas in which money counting, surveillance,
storage and other activities related to the conduct and playing of
games are carried on; "Melbourne Casino Complex" means the Melbourne
Casino and Ancillary Facilities to be constructed on or located within
the Site in accordance with the provisions of this document and the
Casino Agreement; "Melbourne Casino Complex Development Proposals"
means the proposals of the Company in relation to the construction,
development and establishment of the Melbourne Casino Complex, a copy
of which has been signed on behalf of the Authority and the Company
for the purposes of identification; "Minister" means the Minister for
the time being administering the Casino Control Act; "Mortgagee" means
any person other than the State with any Encumbrance (whether as
mortgagee, chargee or otherwise) affecting or in relation to the
Assets and Rights of the Company;
"Operations Agreement" means the agreement dated 30 August 1993 between the
Company and Crown Management Pty Ltd ACN 059 301 610 providing for the conduct
of the operations of the Temporary Casino and the Melbourne Casino; "Permitted
Encumbrance" means an encumbrance permitted under clause 29.1 of the Casino
Agreement; "Planning Amendments" means the planning scheme amendments referred
to in clause 9; "Planning and Environment Act" means the
Planning and Environment Act 1987 (Victoria); "Premium Payment" means $10 000
000 being the amount determined by the Treasurer of the State under
section 112A of the Casino Control Act as the amount payable by the Company
under this document; "Public Authority" means any government or minister or
any governmental, semi-governmental or judicial entity, department,
instrumentality or authority; "Receiver" means receiver, receiver and manager
or agent for a mortgagee in possession, according to the nature of the
appointment; "Secured Property" means at any time, any present or future
right, property or undertaking of the Company, (other than an amount which has
been deposited to, or which is standing to the credit of, the Debt Service
Reserve Account or the Debt Protection Account (each as defined in the
Facility Agreement) and any Authorised Investment (as defined in the Facility
Agreement) from either of those Accounts (or the proceeds of any such
Authorised Investment)) of whatever kind or wherever situated which is subject
at that time to both-
(a) the Fixed and Floating Charge; and
(b) any one or more of the Financiers' Securities; and a reference to
"Secured Property" includes any part of it; "Share" means a fully paid
ordinary share of $0.50 in the capital of the Company;
"Site" means that part of the land bounded by the Yarra River, Clarendon
Street, Whiteman Street and Queensbridge Street in the City of South Melbourne
and more particularly described as part of Crown Allotments 58D and 58E,
County of Bourke, Parish of Melbourne South, City of South Melbourne, as
identified in the draft Plan of Survey annexed as Schedule Three; "Site Lease"
means the lease of the Site from the Minister for Finance on behalf of the
State to the Company; "Site Lease Supplemental Agreement" means the agreement
between the Minister for Finance on behalf of the State, the Company and the
Agent; "Sponsors" mean Hudson Conway Limited ACN 009 556 629 and The Federal
Hotels Limited ACN 004 108 249; "Sponsor's Guarantees" means the guarantees by
Hudson Conway Limited in favour of the Authority and in favour of the State;
"State" means the State of Victoria; "State's Nominated Representative" means
the person appointed from time to time under clause 6.4; "Supplemental
Development Agreement" means the agreement between the State, the Company, the
Sponsors and Hudson Conway Management Limited ACN 006 742 294 which is
supplemental to the Development Agreement; "Supplemental Operations Agreement"
means the agreement between the Authority, the Company, the Sponsors and Crown
Management Pty Ltd ACN 059 301 610 which is supplemental to the Operations
Agreement; "Supplemental Sponsors' Agreement" means the agreement between the
Authority, the Company and the Sponsors which is supplemental to the Founding
Shareholders Agreement; "Temporary Casino" means those areas identified in the
Drawings of the Temporary Casino Complex as the areas which constitute a
casino and includes the areas in which money counting, surveillance, storage
and other activities related to the conduct and playing of games are carried
on; "Temporary Casino Complex" means the Temporary Casino and Ancillary
Facilities to be constructed on or located within the Temporary Casino Site in
accordance with the provisions of the Casino Agreement; "Temporary Casino
Complex Development Proposals" means the proposals of the Company in relation
to the construction, development and establishment of the Temporary Casino
Complex a copy of which has been signed on behalf of the Authority and the
Company for the purposes of identification; "Temporary Casino Leases" means-
(a) the lease from the Port of Melbourne Authority to the Company; and
(b) the sub-lease between the Urban Land Authority, Allco Nominees (Vic)
Pty Ltd ACN 006 837 289 and the Company; "Temporary Casino Leases
Supplemental Agreements" means-
(a) the agreement between the Port of Melbourne Authority, the Company and
the Agent; and
(b) the Temporary Casino Sub-lease Supplemental Agreement; "Temporary
Casino Site" means that part of the World Trade Centre on the land
bounded by Spencer Street, Flinders Street Extension and the River
Yarra identified in the Plan of Survey annexed to the lease referred
to in paragraph (a) of the definition of Temporary Casino Leases;
"Temporary Casino Sub-lease Supplemental Agreement" means the
agreement between the Urban Land Authority, Allco Nominees (Vic) Pty
Ltd ACN 006 837 289, the Company and the Agent; "Transaction Document"
means each of this document, the Casino Agreement, the Casino Licence,
the Site Lease, the Temporary Casino Leases, the Fixed and Floating
Charge, the Sponsor' s Guarantees, the Master Security Agreement, the
Site Lease Supplemental Agreement, the Temporary Casino Leases
Supplemental Agreements, the Supplemental Sponsors' Agreement, the
Supplemental Development Agreement, the Contractor' s Deed, the Bank
Guarantees and the Supplemental Operations Agreement; "Underwriting
Agreement" means both the underwriting agreements of 13 August 1993
and 23 August 1993 between the Company, E. L. & C. Baillieu Limited
ACN 006 519 393, Rothschild Australia Securities Limited ACN 008 591
768, Macquarie Underwriting Limited ACN 001 374 572, Ord Minnett
Securities Limited ACN 003 245 234, James Capel Australia Limited ACN
002 786 272 and the Sponsors; and "Warranties" means the
representations and warranties of the Company set out in Schedule
Four.
3. Operation of provisions
3.1. This clause and clauses 2, 4, 5, 9 and 25 40 (inclusive) commence on the
date of this document.
3.2. Following satisfaction or waiver of the conditions in clauses 5.1(a)
(except for the execution of the Construction Agreement, the Contractor' s
Deed, the Site Lease and the Site Lease Supplemental Agreement) a minister of
the State must-
(a) introduce and sponsor in the Parliament of Victoria a bill to ratify
this document and endeavour to secure its passage as an Act prior to
31 December 1993; and
(b) introduce and sponsor in the Parliament of Victoria a bill contiguous
to the bill referred to in paragraph (a) to amend the
Casino Control Act and endeavour to secure its passage as an Act prior
to 31 December 1993.
3.3. The provisions of this document other than those referred to in clause
3.1 will come into operation on the day on which all of the conditions
precedent in clause 5.1 are satisfied.
3.4. If by 31 December 1993 or such later date as may be agreed by the parties
in writing those parts of the Agreement Act and the Further Amendment Act
which relate to the construction, Fit-Out, Commissioning, Completion and
operation of the Melbourne Casino Complex and the Temporary Casino Complex
each in the form and substance reasonably satisfactory to the Company to
enable the Company to comply with its obligations under the Transaction
Document have not come into operation, this document will terminate.
3.5. Unless termination under clause 3.4 arose because of a failure to satisfy
the conditions in clause 5.1(a) or (b), following that termination neither
party shall have any claim against the other with respect to any matter or
thing antecedent to or arising out of or done, performed or omitted to be done
or performed under this document.
4. Variation
4.1. Subject to clauses 4.2 and 4.3, the parties may from time to time by
agreement in writing vary any provision of this document.
4.2. A minister of the State must introduce and sponsor a bill in the
Parliament of Victoria to ratify any agreement made pursuant to clause 4.1 as
soon as reasonably practicable following its execution.
4.3. The provisions of any agreement made pursuant to clause 4.1 shall come
into operation once the bill referred to in clause 4.2 has come into operation
as an Act.
4.4. Clauses 4.2 and 4.3 shall not apply to the giving of a waiver, a failure
of a party to require full or part performance of an obligation or the
granting of or agreement to an extension of time under this document.
5. Conditions precedent
5.1. This document (other than clauses 2, 4, 5, 9 and 25 40 (inclusive)) is
subject to the satisfaction or waiver by the parties, as conditions precedent,
of all of the following conditions-
(a) the execution of-
(i) the Transaction Documents except for the Casino Licence and the Bank
Guarantees;
(ii) the Finance Documents;
(iii) the Development Agreement;
(iv) the Operations Agreement;
(v) the Construction Agreement;
(vi) the Founding Shareholders Agreement;
(vi) the Underwriting Agreement;
(vii) the Equity Funding Agreement (Federal)-as defined in the Casino
Agreement;
(viii) the Shareholders Agreement-Crown Management Pty Ltd as defined in
the Casino Agreement; and
(ix) the Guarantee and Indemnity for Development Agreement as defined in
the Casino Agreement;
(b) each of the conditions precedent in each document referred to in
paragraph (a) being satisfied other than-
(i) conditions precedent contained in paragraphs (14), (15), and (28) of
Part 1 of Appendix A to and clause 4.2 of the Facility Agreement and
those conditions precedent in Appendix A to the Facility Agreement
that are factual or procedural matters that cannot be satisfied until
the time of drawdown; and
(ii) the issue of the Casino Licence;
(c) approval of the Planning Amendments; and
(d) the coming into operation of those parts of the Agreement Act and the
Further Amendment Act which relate to the construction, Fit-Out,
Commissioning, Completion and operation of the Melbourne Casino
Complex and the Temporary Casino Complex each in the form and
substance reasonably satisfactory to the Company to enable the Company
to comply with its obligations under the Transaction Documents.
5.2. Subject to clause 5.3, if all of the conditions in clause 5.1 are not
satisfied or waived on or before 31 December 1993 or such later date agreed by
the parties in writing, then either party may terminate this document by
notice in writing to the other party.
5.3. A party cannot exercise the right of termination referred to in clause
5.2 where any of the conditions in clause 5.1 remain unsatisfied due to an act
or omission of that party. PART 2-APPROVAL OF DEVELOPMENT PROPOSALS AND CASINO
LOCATION
6. Design and planning objectives
6.1. The parties acknowledge that the Melbourne Casino Complex Development
Proposals and the Temporary Casino Complex Development Proposals and the
Drawings describe the Company' s proposals for the design, development,
construction, Fit-Out and Commissioning of the Melbourne Casino Complex and
the Temporary Casino Complex.
6.2. The Company must develop the Melbourne Casino Complex and the Temporary
Casino Complex in accordance with the requirements of this document and the
Casino Agreement.
6.3. The Company acknowledges that it is required to obtain approvals under
the Control Acts and otherwise comply with the Control Acts.
6.4. The State shall procure that the minister for the time being
administering the Planning and Environment Act appoints a person who will
represent the persons responsible for the granting of approvals under or
otherwise administering the Control Acts.
6.5. The Company may deliver all documents and other information required to
obtain approvals or to otherwise comply with the Control Acts to the State's
Nominated Representative.
6.6. The State's Nominated Representative shall use its best endeavours to
procure the making of all decisions required to be made under the Control Acts
in respect of the obligations of the Company under clause 6.2.
6.7. The State shall procure that the State's Nominated Representative
complies with the obligations of the State's Nominated Representative under
the Casino Agreement.
7. Approval of the casino site The State approves-
(a) the Site as the site upon which the Melbourne Casino Complex will be
developed in accordance with the Melbourne Casino Complex Development
Proposals, the relevant Planning Amendments and the requirements of
this document and the Casino Agreement; and
(b) the Temporary Casino Site as the site upon which the Temporary Casino
Complex will be developed in accordance with the Temporary Casino
Complex Development Proposals, the relevant Planning Amendments and
the requirements of this document and the Casino Agreement.
8. Identification of casino On and subject to the provisions of this document
and the Casino Agreement, the State approves of the grant by the Authority to
the Company of the Casino Licence which provides for a casino to be located at
the Temporary Casino and then at the Melbourne Casino.
9. Zoning
9.1. The Minister will recommend to the minister administering the
Planning and Environment Act that a planning scheme amendment be prepared,
adopted and approved by the minister administering the
Planning and Environment Act to allow the use and development of the Site for
the purposes of the Melbourne Casino Complex generally in accordance with the
Melbourne Casino Complex Development Proposals.
9.2. The Minister will recommend to the minister administering the
Planning and Environment Act that a planning scheme amendment be prepared,
adopted and approved by the minister administering the
Planning and Environment Act to allow the use and development of the Temporary
Casino Site for the purposes of the Temporary Casino Complex generally in
accordance with the Temporary Casino Complex Development Proposals.
9.3. Section 38 of the Planning and Environment Act will not apply to the
Planning Amendments.
9.4. Clause 9.3 will not apply if the Planning Amendments are approved prior
to the beginning of the 1993 Spring Parliamentary session. PART 3-DEVELOPMENT
10. Development conditions
10.1. The Company must-
(a) Construct, Fit-Out, Commission and Complete the Melbourne Casino
Complex in accordance with-
(i) the Melbourne Casino Complex Development Proposals, the Drawings and
the further working drawings and specifications provided to the State
and the Authority together with any approved variations;
(ii) the Design and Construction Programme;
(iii) the Planning Amendments; and
(iv) the terms of this document and the Casino Agreement;
(b) Complete the Melbourne Casino by the Completion Date; and
(c) Complete the Melbourne Casino Complex by the Completion Date.
10.2. The Company must-
(a) Construct, Fit-Out, Commission and Complete the Temporary Casino
Complex in accordance with-
(i) the Temporary Casino Complex Development Proposals, the Drawings and
the further working drawings and specifications provided to the State
and the Authority together with any approved variations;
(ii) the Design and Construction Programme;
(iii) the Planning Amendments; and
(iv) the terms of this document and the Casino Agreement;
(b) Complete the Temporary Casino by the Completion Date; and
(c) Complete the Temporary Casino Complex by the Completion Date.
11. Documents to be submitted to the State's Nominated Representative
11.1. The Company must provide to the State's Nominated Representative for the
approval or otherwise of the State's Nominated Representative-
(a) within 12 weeks following the Licensing Date, such drawings,
specifications and other documents as are required by the State's
Nominated Representative so that the State's Nominated Representative
may be satisfied that the Melbourne Casino Complex and the Temporary
Casino Complex will be Completed in accordance with this document; and
(b) within 12 weeks following the Licensing Date, an itemised Design and
Construction Programme for all phases of the development of the
Melbourne Casino Complex and the Temporary Casino Complex up to and
including Completion.
11.2. On the first Business Day of each month the Company must provide to the
State's Nominated Representative a report in a form satisfactory to the
State's Nominated Representative as to the progress of construction of the
Melbourne Casino Complex and the Temporary Casino Complex.
12. Approvals
12.1. Where the Company submits documents to the State's Nominated
Representative under clause 11.1, the State's Nominated Representative may-
(a) approve the documents;
(b) approve the documents subject to any reasonable condition or
conditions the State's Nominated Representative decides to impose;
(c) require amendment to the documents as specified by the State's
Nominated Representative; or
(d) reject the documents.
12.2. Where the Company submits documents to the State's Nominated
Representative, the State's Nominated Representative must respond in writing
to the Company in the manner contemplated within 14 days of receiving the
documents or proposal from the Company or such further period agreed between
the State's Nominated Representative and the Company.
12.3. If the State's Nominated Representative has not responded in writing to
the Company as required within 14 days or such further period as agreed the
State's Nominated Representative will be taken to have given its approval.
12.4. In exercising any powers under clauses 12, 15 and 18 the State's
Nominated Representative must not act unreasonably and have regard to the
contents of the Melbourne Casino Complex Development Proposals, the Temporary
Casino Complex Development Proposals and the Planning Amendments.
12.5. Subject to the rights, obligations or powers of the State or the State's
Nominated Representative under the Control Acts and this document including
without limitation the obligations of the Company under clause 13, the State's
Nominated Representative will not impose conditions or amendments which have
the effect of substantially increasing the cost to Complete the Temporary
Casino, the Temporary Casino Complex, the Melbourne Casino or the Melbourne
Casino Complex from the cost to develop, design and construct set out in the
Melbourne Casino Complex Development Proposals and the Temporary Casino
Development Proposals.
13. Quality
13.1. The Company must ensure that all materials, fittings, equipment and
workmanship utilised in carrying out the construction of the Melbourne Casino
Complex-
(a) are of a quality commensurate with an international class casino
complex;
(b) comply with standards specified in the Melbourne Casino Complex
Development Proposals; and
(c) comply with the provisions of the Building Control Act 1981 (Victoria)
and the Building Code of Australia relevant to the materials,
fittings, equipment or workmanship.
13.2. The Company must ensure that all materials, fittings, equipment and
workmanship utilised in carrying out the construction of the Temporary Casino
Complex-
(a) are of a quality commensurate with the proposed use of the Temporary
Casino Site, the nature of the premises on the Temporary Casino Site
and the proposed term of occupation of the Temporary Casino Site by
the Company;
(b) comply with standards specified in the Temporary Casino Complex
Development Proposals; and
(c) comply with the provisions of the Building Control Act 1981 (Victoria)
and the Building Code of Australia relevant to the materials,
fittings, equipment or workmanship.
13.3. The builder to be appointed by the Company in relation to the
construction of the Melbourne Casino Complex or the Temporary Casino Complex,
as the case may be, must be approved in writing by the State's Nominated
Representative prior to the builder' s appointment.
14. Provision of services The Company must-
(a) pay to the State or, as the case may be, the instrumentality of the
State concerned, the costs incurred in carrying out any works
necessary to provide services or change existing services, including
without limitation, water, sewerage, drainage, electricity and gas, to
the Site and the Melbourne Casino Complex; or
(b) if required by the State or the relevant instrumentality, carry out
such works at the Company' s cost and in accordance with all
directions of the State or instrumentality.
15. Completion
15.1. The Company must give not less than 7 Business Days notice in writing to
the State's Nominated Representative that the Company anticipates that the
Temporary Casino, the Temporary Casino Complex, the Melbourne Casino or the
Melbourne Casino Complex, as the case may be, ("Relevant Works") will be
Completed on the date specified in the notice.
15.2. On the date agreed between the Company and the State's Nominated
Representative (and if no date is agreed, then on the date specified in the
Company' s notice under clause 15.1) the State's Nominated Representative must
inspect the Relevant Works and consider all matters relevant to the Completion
of the Relevant Works.
15.3. If the State's Nominated Representative is of the opinion that the
Relevant Works are not Completed, the State's Nominated Representative must
within 10 Business Days of the inspection under clause 15.2 give notice to the
Company of this opinion and state in that notice the reason or reasons why the
State's Nominated Representative is of this opinion.
15.4. If the State's Nominated Representative is of the opinion that the
Relevant Works are Completed, the State's Nominated Representative must within
10 Business Days of the inspection under clause 15.2 issue a certificate to
the Company stating the date on which it believes those Relevant Works reached
Completion and those Relevant Works shall, for the purpose of this document,
be taken to have been Completed on that date.
15.5. Upon receipt of a notice from the State's Nominated Representative under
clause 15.3, the Company must immediately attend to any matters stated in the
notice as requiring attention and upon the Company attending to these matters
the Company must give a further notice in writing to the State's Nominated
Representative pursuant to clause 15.1.
15.6. Any determination by the State's Nominated Representative that any
Relevant Works have been Completed is not acceptance that the Company has
complied with the Transaction Documents and any right which the State or the
State's Nominated Representative may have had prior to that determination is
preserved absolutely.
15.7. If the State's Nominated Representative does not deliver a notice to the
Company under clause 15.3 or a certificate under clause 15.4 within the period
of 10 Business Days referred to in those clauses, the Relevant Works will be
taken to have been Completed on the date on which those Relevant Works were
inspected under clause 15.2 and a certificate of Completion will be taken to
have been issued by the State's Nominated Representative with a date of
Completion on that date.
15.8. A certificate of Completion under clause 15 does not excuse the Company
from compliance with all relevant legislation in relation to the Relevant
Works.
16. Force Majeure
16.1. Provided the Company complies with clause 16.2, the performance by the
Company of the terms and conditions of this document relating to the design,
development, construction, Fit-Out, Commissioning and Completion of the
Temporary Casino, the Temporary Casino Complex, the Melbourne Casino or the
Melbourne Casino Complex, as the case may be, is subject to any Force Majeure
Event which interferes with the performance of those terms and conditions.
16.2. The Company must-
(a) immediately give notice to the State's Nominated Representative of-
(i) a Force Majeure Event and its nature;
(ii) the actual or likely extent and effect of the Force Majeure Event on
the Company' s performance of its obligations in relation to the
matters referred to in clause 16.1;
(iii) the likely duration of the Force Majeure Event;
(b) meet with the State's Nominated Representative within 2 Business Days
of receipt of a request from the State's Nominated Representative to
discuss the Force Majeure Event and attempt to determine what action
if any may be taken to ameliorate, remedy or overcome the Force
Majeure Event; and
(c) use its best endeavours-
(i) to minimise the effect of that Force Majeure Event as soon as possible
after the occurrence; and
(ii) to prevent, overcome or remedy any delay which would or might
otherwise be caused by a Force Majeure Event, including if necessary
by the commitment of additional resources.
16.3. If the Company complies with clause 16.2, the State's Nominated
Representative will by notice in writing to the Company extend the relevant
Completion Date to a date to be specified by the State's Nominated
Representative to allow for any delay caused by the Force Majeure Event and
the Company will not be liable to the State for any delay in the Completion of
the Temporary Casino, the Temporary Casino Complex, the Melbourne Casino or
the Melbourne Casino Complex (as the case may be) for the period from the
Completion Date until the new Completion Date specified by the State's
Nominated Representative.
16.4. If an Extension Event occurs which is not a Force Majeure Event but
which delays the performance by the Company of any of the terms and conditions
of this document relating to the design, development, construction, Fit-Out,
Commissioning or Completion, the relevant Completion Date shall be extended by
the period it would take a reasonable person acting diligently to overcome or
remedy the delay, provided that the Company-
(a) as soon as reasonably practicable after becoming aware of the
occurrence of the event gives notice to the State of-
(i) the event and its nature;
(ii) the actual or likely extent and effect of the event on Completion; and
(iii) the likely delay to Completion; and
(b) pays Liquidated Damages to the State in accordance with clause 17.2.
16.5. The cessation of casino operations by the Company at the Temporary
Casino after the Completion of the Temporary Casino caused directly or
indirectly by an Extension Event which results in the physical destruction of
all or a material part of the Temporary Casino shall not be a contravention of
a condition of the Casino Licence or any Transaction Document provided that
the Company-
(a) as soon as reasonably practicable after becoming aware of the
occurrence of the Extension Event gives notice to the State of-
(i) the Extension Event and its nature;
(ii) the actual or likely extent and effect of the Extension Event on the
operations of the Temporary Casino; and
(iii) the likely duration of the cessation of operations of the Temporary
Casino;
(b) commences reinstatement of the Temporary Casino within 3 months of the
date of the cessation of the Extension Event; and
(c) if paragraph (b) applies, the Company is diligently proceeding with
the construction of the reinstatement of the Temporary Casino;
provided that paragraphs (b) and (c) shall apply subject to any
requirements or actions of the lessors or sub-lessors under the
Temporary Casino Leases, the relevant insurers, or any authorities and
if it is practicable and permitted by each relevant lessor or
sub-lessor and each other applicable authority for the Company to
reinstate or attempt to reinstate the Temporary Casino.
16.6. The cessation of casino operations by the Company at the Melbourne
Casino after the Completion of the Melbourne Casino caused by an Extension
Event which results in the physical destruction of all or a material part of
the Melbourne Casino shall not be a contravention of a condition of the
Casino Licence or any Transaction Document provided that-
(a) as soon as reasonably practicable after becoming aware of the
occurrence of the Extension Event the Company gives notice to the
State of-
(i) the Extension Event and its nature;
(ii) the actual or likely extent and effect of the Extension Event on the
operations of the Melbourne Casino; and
(iii) the likely duration of the cessation of operations of the Melbourne
Casino;
(b) if requested by the State within 1 month of the occurrence of the
Extension Event, the Company must submit a proposal to the State
within 3 months of the State's request for the construction of a
replacement temporary casino ("Replacement Temporary Casino");
(c) if the Company, the State and the Financiers have agreed, as
contemplated in clause 16.7, on the basis for the construction of the
Replacement Temporary Casino, the Company completes the construction
of the Replacement Temporary Casino within the time periods agreed in
relation thereto; and
(d) the Company commences reinstatement of the Melbourne Casino within 12
months of the date of the cessation of the Extension Event, subject to
any requirements of the relevant insurers or any authorities, and
diligently pursues a course of action which will reasonably be
expected to reinstate the Melbourne Casino in a period of time
reasonably acceptable to the State and is making satisfactory progress
in the reinstatement.
16.7. The Company, the State and the Financiers shall consult in good faith in
relation to the Company's proposal submitted under clause 16.6(b) to agree on
the terms for the establishment and operation of the Replacement Temporary
Casino including-
(a) the site of the Replacement Temporary Casino;
(b) the size, features and specifications of the Replacement Temporary
Casino;
(c) the amendments to the Transaction Documents and the additional
documents necessary (including the issue of a new casino licence under
the Casino Control Act);
(d) all planning and zoning approvals, permits and requirements;
(e) any extensions of the exclusivity periods for the Casino Licence; and
(f) the cost of the Replacement Temporary Casino and the funding of those
costs.
16.8. For the purposes of this document-
(a) "Extension Event" means-
(i) a Force Majeure Event;
(ii) a Labour Dispute where the Labour Dispute could not have been
prevented, overcome or remedied by the exercise by the affected party
of a standard of care and diligence consistent with that of a prudent,
experienced and competent person; or
(iii) any other event or circumstance which causes disruption, illegality
or physical damage and which is outside the control of the Company and
has not been directly or indirectly caused by an act or omission of
the Company;
(b) "Labour Dispute" means a strike, lockout, industrial dispute, labour
dispute, industrial difficulty, labour difficulty, work ban, blockage,
picketing action, secondary boycott or any other labour action or lack
of action.
16.9 (a) The Company agrees that the proceeds of any insurance policy for business interruption insurance taken out by or on behalf of the Company will, on receipt by the Company, be paid to the State in compensation to the State for the loss of fees and taxes calculated for a period in accordance with paragraph (b) and otherwise to the Agent in respect of moneys owing to the Financiers under the Finance Documents.
(b) The amount of the insurance proceeds received by the Company in
respect of a period which shall be paid as compensation to the State
under paragraph (a) for that period shall be an amount equal to 20%
(and after 1 July 1997, 211/4%) of the amount of the assumed Gross
Gaming Revenue for that period, based on the assumption that Gross
Gaming Revenue had been earned at the average daily rate calculated
for the six months period immediately prior to the commencement of
that period.
17. Liquidated damages
17.1. Subject only to clause 16.3, if the Company fails to Complete and open
for business-
(a) the Temporary Casino by the Completion Date; or
(b) the Melbourne Casino by the Completion Date, the State's Nominated
Representative may give notice in writing to the Company that this
clause 17 is to apply.
17.2. If a notice is given under clause 17.1 the Company must pay to the State
liquidated damages-
(a) in the event that the Temporary Casino is not Completed and open for
business by the Completion Date (as varied by any Force Majeure Event
pursuant to clause 16.3), at the rate of $50 000 for each day from
that date to the date the Temporary Casino is Completed and open for
business; and
(b) in the event that the Melbourne Casino is not Completed and open for
business by the Completion Date (as varied by any Force Majeure Event
pursuant to clause 16.3), at the rate of $50 000 for each day from
that date to the date the Melbourne Casino is Completed and open for
business.
17.3. The parties agree that the liquidated damages calculated and provided
for in clause 17.2-
(a) constitute a genuine pre-estimate of the loss or damage anticipated to
be actually suffered by the State if the Company breaches its
obligations to Complete and open for business the Temporary Casino or
the Melbourne Casino by the respective Completion Dates;
(b) are intended to avoid the cost and difficulty of proof of damages in
the event of that breach;
(c) are reasonable and not intended to be a penalty; and
(d) subject to clause 25.5, are the only damages payable by the Company
for late Completion.
17.4. If all payments due under clause 17.2 are made, then notwithstanding
clause 25.2(a), the Authority shall not be entitled to serve a notice pursuant
to section 20(2) of the Casino Control Act by reason of the Company failing to
comply with clause 10.1 if-
(a) completion of the Melbourne Casino Complex has occurred within a
period of 12 months commencing on the Completion Date;
(b) the Authority is not entitled to do so under the Master Security
Agreement; or
(c) the failure to comply with clause 10.1 was caused by an Extension
Event subject to compliance with such other obligations as arise under
clause 16.
18. Bank guarantee
18.1. In order to secure the obligations of the Company under clause 17.2 of
this document to pay liquidated damages, the Company must on or before the
Licensing Date provide to the State an unconditional guarantee or letter of
credit issued by a bank or banks acceptable to the State's Nominated
Representative and in such form approved by the State's Nominated
Representative to pay to the State on demand up to $25 000 000.
18.2. Unless demand under the Bank Guarantee has been previously made and has
not been satisfied, the Bank Guarantee will be returned to the Company 18
months after the Melbourne Casino Complex has been Completed.
19. Off-Site Works
19.1. The Company must, at the cost of the Company, construct and complete or
procure the construction and completion of the Off-Site works specified in the
Melbourne Casino Complex Development Proposals, the Temporary Casino Complex
Development Proposals and Schedule Five ("Off-Site Works") in accordance with
the terms of this clause 19 and the reasonable requirements of the State.
19.2. The Company must prepare all plans, specifications and computations
necessary for the obtaining of all relevant approvals.
19.3. Subject to clause 19.8, the State will issue or procure the issue of all
approvals within its power in order that the Off-Site Works may be completed.
19.4. Subject to clauses 19.5 to 19.7 (inclusive), the Company must construct,
complete and maintain the Off-Site Works such that-
(a) subject to paragraph (c), in the case of those Off-Site Works which
relate to the Temporary Casino Complex or the Temporary Casino, the
Off-Site Works are constructed promptly and their construction
completed so as to coincide with the Completion and opening for
business of the Temporary Casino;
(b) subject to paragraph (c), in the case of those Off-Site Works which
relate to the Melbourne Casino Complex or the Melbourne Casino, the
Off-Site Works are constructed promptly and their construction
completed so as to coincide with the Completion and opening for
business of the Melbourne Casino;
(c) each item of Off-Site Works is to be constructed and completed by a
date that the State may reasonably direct having regard to-
(i) the nature of that item of Off-Site Works;
(ii) the impact the completion of that item of Off-Site Works will have on
the amenity of the area where that item of Off-Site Works will be
located; and
(iii) the desirability of having that item of Off-Site Works completed
having regard to the community' s need for it; and
(d) the Off-Site Works are to be constructed, completed and maintained by
the Company in compliance with the Control Acts and the Planning
Amendments using all materials, fittings, equipment and workmanship
that-
(i) are of a similar standard to those used in constructing the Melbourne
Casino Complex;
(ii) are of a standard specified in Schedule Five, the Melbourne Casino
Complex Development Proposals and the Temporary Casino Complex
Development Proposals; and
(iii) comply with the provisions of the Control Acts and the Building Code
of Australia relevant to the materials, fittings, equipment or
workmanship.
19.5. The State may give a notice to the Company by 31 March 1994 excluding
the Queensbridge Square Access Tunnel identified as part of the Off-Site Works
described in Schedule Five ("Tunnel") from the obligations referred to in
clauses 19.1 to 19.4 and the Company shall not and will not be obliged to
construct or complete the Tunnel.
19.6. In consideration of the State excluding the Tunnel from the obligations
referred to in clauses 19.1 to 19.4, the Company shall pay to the State the
amount identified in item 6 of the Off-Site Works applicable to the Tunnel
within 30 days from the date of the notice given by the State pursuant to
clause 19.5.
19.7. The State may give a notice to the Company by 31 March 1994 excluding
the Modification to North River Bank identified as part of the Off-Site Works
described in Schedule Five ("North River Bank Modifications") from the
obligations referred to in clauses 19.1 to 19.4 and the Company shall not and
will not be obliged to construct, complete or maintain the North River Bank
Modifications and the State shall not be entitled to any payment in lieu of
the exclusion of the North River Bank Modifications.
20. Use of Melbourne Casino Complex following completion
20.1. Following Completion of the Melbourne Casino Complex, the Company must
use all reasonable endeavours and have the firm objective at all times to-
(a) do all things necessary or desirable to ensure that all parts of the
Melbourne Casino Complex are fully let and are kept let in accordance
with the Melbourne Casino Complex Development Proposals and the
relevant Planning Amendments;
(b) ensure that there is at all times a variety of retail businesses
operating from or in the Melbourne Casino Complex of a type and nature
necessary to attract customers and tourists to the Melbourne Casino
Complex consistent with the use of the Melbourne Casino Complex as a
high quality, international class casino complex; and
(c) ensure that each business in the Melbourne Casino Complex is kept open
for business and carried on in a manner compatible with and
complementary to the use of the Melbourne Casino Complex as a high
quality, international class casino complex.
20.2. Following Completion of the Melbourne Casino Complex, the Company must
at all times-
(a) advertise and promote the Melbourne Casino Complex so as to endeavour
to ensure that the Melbourne Casino Complex is fully and regularly
patronised; and
(b) properly and diligently manage the Melbourne Casino Complex in
accordance with good, modern and proven management methods and
practices and with due skill, expertise, diligence and vigour, using
good and sufficient materials and services and in strict accordance
and compliance with all applicable laws, regulations and requirements.
PART 4-PAYMENTS TO THE STATE
21. Payments on the Licensing Date
21.1. In consideration of the agreement of the Authority to grant to the
Company the Casino Licence and of the other assurances from the State and the
Authority contained in this document and the Casino Agreement, the Company
shall pay on the Licensing Date-
(a) the Premium Payment; and
(b) a further amount of $190 000 000.
21.2. The Licensing Payment Amounts must be paid in same day settlement funds
before 2.00 p.m. on the Licensing Date.
21.3. If the Company fails to pay the Licensing Payment Amounts on the
Licensing Date, without prejudice to any other right or remedy arising because
of that failure, the Company must pay to the State interest (calculated daily)
on the amount in default (including accrued interest) at the Default Rate for
the period from the Licensing Date until the Licensing Payment Amounts and all
interest payable have been paid.
22. Amount of fees and taxes
22.1. While the Casino Licence remains in force, the Company must pay-
(a) to the State, for each Financial Year or part thereof until 30 June
1997, the Casino Supervision and Control Charge, the first payment
being due and payable on the Licensing Date in respect of the period
until 30 June 1994 and thereafter the Casino Supervision and Control
Charge will be paid annually in advance, commencing on 1 July 1994;
(b) to the State, in respect of each month in which gaming is conducted in
the Temporary Casino or the Melbourne Casino, casino tax in an amount
equal to-
(i) for the period until 30 June 1997, 20% of the Gross Gaming Revenue for
the month in question; and
(ii) on and from 1 July 1997, 211/4% of the Gross Gaming Revenue for the
month in question; payable in each case within 7 days following the
end of each month, the first payment to be made in relation to the
month in which the Temporary Casino is Completed;
(c) to the State, in respect of each month beginning on 1 July 1994 and
ending on 30 June 1996 additional casino tax in an amount of $2 400
000 payable within 7 days of the end of each month;
(d) to the State, in respect of each month in which gaming is conducted in
the Temporary Casino or the Melbourne Casino, a community benefit levy
in an amount equal to 1% of the Gross Gaming Revenue for the month in
question, on the same dates as payments are made to the State pursuant
to paragraph (b); and
(e) any other fees and payments payable under the Casino Control Act.
22.2. In addition to the casino tax payable under clause 22.1(b), while the
Casino Licence remains in force the Company must pay to the State in respect
of each Financial Year in which Gross Gaming Revenue exceeds the Base Amount,
additional casino tax calculated in accordance with clause 22.3.
22.3. In this clause 22 "Base Amount" means, subject to clause 22.6-
(a) to 30 June 1994, $500 000 000; and
(b) on 1 July 1994 and each anniversary of that date ("Review Date") the
amount determined at any time after that review date in accordance
with the following formula: R = A/B x C where-
R is the Base Amount in respect of the year commencing on the relevant Review
Date;
A is the Consumer Price Index (All Groups for Melbourne) published from time
to time in the Australian Statistician' s Summary of Australian Statistics
("CPI Index") published for the day immediately preceding the relevant Review
Date;
B is the CPI Index for the day one year and one day prior to the relevant
Review Date; and
C is the Base Amount (as amended from time to time in accordance with this
clause) for the year immediately preceding the relevant Review Date.
22.4. The amount of the additional casino tax payable under clause 22.2 shall
be calculated in accordance with the following table- Amount of EGGR $ Amount
of additional casino tax $ Nil - 19 999 999 Nil + 1% of the Excess 20 000 000
- 39 999 999 200 000 + 2% of the Excess 40 000 000 - 59 999 999. 600 000 + 3%
of the Excess 60 000 000 - 79 999 999 1 200 000 + 4% of the Excess 80 000 000
- 99 999 999 2 000 000 + 5% of the Excess 100 000 000 - 119 999 999 3 000 000
+ 6% of the Excess 120 000 000 - 139 999 999 4 200 000 + 7% of the Excess 140
000 000 - 159 999 999 5 600 000 + 8% of the Excess 160 000 000 - 179 999 999 7
200 000 + 9% of the Excess 180 000 000 - 199 999 999 9 000 000 + 10% of the
Excess 200 000 000 - 219 999 999 11 000 000 + 11% of the Excess 220 000 000 -
239 999 999 13 200 000 + 12% of the Excess 240 000 000 - 259 999 999 15 600
000 + 13% of the Excess 260 000 000 - 279 999 999 18 200 000 + 14% of the
Excess 280 000 000 - 299 999 999 21 000 000 + 15% of the Excess 300 000 000 -
319 999 999 24 000 000 + 16% of the Excess 320 000 000 - 339 999 999 27 200
000 + 17% of the Excess 340 000 000 - 359 999 999 30 600 000 + 18% of the
Excess 360 000 000 - 379 999 999 34 200 000 + 19% of the Excess 380 000 000 or
more 38 000 000 + 20% of the Excess where- "EGGR" is the amount by which Gross
Gaming Revenue in a Financial Year exceeds the Base Amount for that Financial
Year; and "Excess" means in respect of any row in the above table, the amount
by which EGGR exceeds the number first appearing in the first column of that
row.
22.5. The casino tax calculated under clause 22.4 and payable under clause
22.2 must be paid to the State within 7 days following the end of each
Financial Year.
22.6. If the Australian Statistician updates the reference base for the CPI
Index an appropriate adjustment shall be made to the definition of "Base
Amount" in clause 22.3 to preserve the intended continuity of calculation by
using an alternative appropriate factor determined by the Statistician in lieu
of "A/B" in the definition of "Base Amount".
22.7. If the CPI Index referred to in the definition is discontinued,
suspended or otherwise altered to such an extent that an adjustment under
clause 22.6 cannot in the reasonable opinion of the State be made, the Base
Amount shall be determined by substituting for "A/B" in the definition of
"Base Amount" such other comparable index as the State may reasonably require.
22.8. The Casino Supervision and Control Charge will not be levied on the
Company after 1 July 1997.
22.9. To secure to the State the payment of the additional casino tax pursuant
to clause 22.1(c), the Company must on or before the Licensing Date provide to
the State an unconditional letter of credit issued by a bank or banks
acceptable to the State's Nominated Representative and in such form approved
by the State's Nominated Representative to pay to the State an amount not less
than $57 600 000 provided that the amount required to be secured to the State
by the letter of credit from time to time shall be reduced by an amount equal
to each amount of exclusivity casino tax paid under this document. PART
5-EXCLUSIVITY
23. Exclusivity period and area
23.1. The Minister approves of the undertaking given by the Authority to the
Company under clause 26.2 of the Casino Agreement.
23.2. Subject to clauses 23.3 and 24 and to the rights conferred on the
Company under the Casino Agreement and the Casino Licence, while the
Casino Licence remains in force the conduct or playing of any game approved by
the Authority under section 60 of the Casino Control Act or the use of any
premises for the conduct and playing of any such game shall not be permitted
by the State-
(a) within the State prior to 6 years from the Licensing Date; and
(b) for those parts of the State within a radius of 150 kilometres from
the Site, prior to 12 years from the Licensing Date.
23.3. If clause 26.3 of the Casino Agreement applies, the exclusivity periods
referred to in clause 23.2 shall be extended to the same dates that the
exclusivity periods in clause 26.2 of the Casino Agreement are extended under
clauses 26.3 and 26.4 of the Casino Agreement (if any).
24. Existing games
24.1. Nothing in this document shall be construed so as to limit or affect the
power of the State to authorise, permit or approve in any manner whatever-
(a) the playing on any gaming machines (in accordance with the provisions
of the Gaming Machine Control Act 1991 (Victoria)) of-
(i) any game not referred to in clause 27.1 of the Casino Agreement;
(ii) any machine derivative of any game not referred to in clause 27.1 of
the Casino Agreement; or
(iii) any machine derivative of any game referred to in clause 27.1 of the
Casino Agreement which is played on a gaming machine at the date of
this document;
(b) any lottery, bingo or other game approved or permitted under the
Lotteries Gaming and Betting Act 1966 (Victoria);
(c) any sweepstake, lottery or other game approved or permitted under the
Tattersall Consultations Act 1958 (Victoria);
(d) the conduct of the game of club keno in accordance with the Club Keno
Act 1993 (Victoria); or
(e) any other game which may legally be played or conducted in the State
of Victoria as at the date of this document.
24.2. Notwithstanding clause 24.1, the State shall restrict the playing of
gaming machines within the following limits-
(a) during the period prior to the date 12 years from the Licensing Date,
the maximum number of gaming machines permitted to be used at any
approved venue located within a radius of 100 kilometres from the Site
shall be 105; and
(b) the total number of gaming machines permitted to be used in the State
during the period prior to the date 12 years from the Licensing Date
shall not exceed 45 000. PART 6-TERMINATION
25. Termination of this document
25.1. This document will automatically terminate-
(a) without notice to the Company, if the Casino Licence is-
(i) surrendered; or
(ii) cancelled; or
(b) when the Casino Licence expires due to the effluxion of time. Such
termination, however, does not affect the ability of either party to
enforce a right which may have accrued to it under this document prior
to such termination.
25.2. Subject to the Master Security Agreement, it shall be a contravention of
a condition of the Casino Licence enabling the Authority to serve a notice on
the Company pursuant to section 20(2) of the Casino Control Act if any of the
following events occurs-
(a) the Company commits a breach of any provision of this document and the
State has given a notice ("Notice") to the Company detailing the
particulars of the breach unless-
(i) if the breach is capable of remedy-
(A) it is remedied within the cure period allowed in the
Notice (which shall not be less than 60 days) to the
reasonable satisfaction of the State; or
(B) the Company-
(i) is diligently pursuing a course of action which could reasonably be
expected to remedy the breach in a period of time reasonably
acceptable to the State; and
(ii) is making satisfactory progress with such course of action; or
(ii) if the breach to which the Notice refers is not capable of remedy-
(A) the Company is complying to the reasonable satisfaction
of the State with any reasonable requirements of the
State in relation to the breach or is attending to the
reasonable redress of the prejudice arising from the
breach, default or event in the manner specified in the
Notice; or
(B) the payment of damages constitutes in the reasonable
opinion of the State proper redress and the required
amount of damages is paid within 15 Business Days of the
date for payment as specified in the Notice;
(b) any of the following occurs and the Company does not within 10
Business Days of the occurrence of the event establish to the
reasonable satisfaction of the State that despite the occurrence of
the event the Company will be able to perform its obligations under
the Transaction Documents-
(i) a provisional liquidator or administrator is appointed to the Company;
(ii) a Receiver is appointed to any of the Casino Assets;
(iii) any Encumbrance becomes enforceable and the holder of the Encumbrance
takes possession of any of the Casino Assets;
(iv) a judgment is obtained against the Company and execution or other
process of any Court or other authority is issued against or is levied
or enforced upon any of the Casino Assets;
(c) a liquidator is appointed to the Company;
(d) prior to Completion, the Financiers terminate their obligations under
the Facility Agreement, or otherwise permanently refuse to permit any
further drawings under the Facility Agreement or the facilities
provided or available under the Facility Agreement, and the Company
does not within 20 Business Days of the occurrence of the event
establish to the reasonable satisfaction of the Authority that despite
the occurrence of the event the Company will be able to perform its
obligations under the Transaction Documents;
(e) a Notice of Intention pursuant to the Supplemental Development
Agreement is given by the Developer under that agreement and is not
withdrawn within 10 Business Days;
(f) a Notice of Intention pursuant to the Contractor' s Deed is given by
the Contractor under that agreement and is not withdrawn within 10
Business Days;
(g) except with the prior consent in writing of the Authority the members
resolve to wind up the Company;
(h) the Site Lease is terminated or surrendered;
(i) prior to Completion of the Melbourne Casino any one of the Temporary
Casino Leases is terminated (other than by effluxion of time) or
surrendered;
(j) prior to the subscription by the Founding Shareholders for all the
Shares for which they have agreed to subscribe under the Founding
Shareholders Agreement, any of the following occurs and the Company
does not within 10 Business Days after the State has given notice to
the Company remedy the event or redress the prejudice arising from the
event or establish to the reasonable satisfaction of the Authority
that despite the occurrence of the event the Company will be able to
perform its obligations under the Transaction Documents-
(i) a Founding Shareholder fails to comply with any obligation to
subscribe for Shares in accordance with the provisions of the Founding
Shareholders Agreement;
(ii) a Receiver, provisional liquidator, liquidator or administrator is
appointed to a Sponsor;
(iii) except with the prior consent in writing of the Authority the members
resolve to wind up a Sponsor;
(k) Shares having an aggregate subscription amount of $210 000 000 have
not been subscribed for by the Licensing Date by persons other than
the Founding Shareholders and within 10 Business Days of the Licensing
Date the Company has not established to the reasonable satisfaction of
the State that the Company will despite this be able to perform its
obligations under the Transaction Documents.
25.3. The State may in its absolute discretion extend any time period referred
to in clause 25.2.
25.4. Subject to clause 26, on termination of this document-
(a) except as otherwise provided by this document all rights of the
Company to, in or under this document will cease but without prejudice
to the liability of any party in respect of any antecedent breach or
default under this document or in respect of any indemnity or other
payment obligation under this document;
(b) all moneys owing or remaining unpaid (and whether actually or
contingently) to the State will (to the extent not then due) become
immediately due and payable and the Company must immediately pay all
those moneys to the State; and
(c) except as otherwise provided in this document or the Master Security
Agreement, neither the Company nor any Sponsor or any other person
will have any claim against the State or both with respect to any
matter or thing in or arising out of this document and in particular,
but without limiting the generality of the preceding paragraphs, the
Company will have no claim to the repayment of all or any part of the
Licensing Payment Amounts.
25.5. Without limiting the powers of the State under the Fixed and Floating
Charge, if this document is terminated prior to Completion of the Temporary
Casino Complex or the Melbourne Casino Complex and a Mortgagee does not agree
to or does not Complete the Temporary Casino Complex or the Melbourne Casino
Complex or both (as the case may be) in accordance with the Master Security
Agreement or otherwise on terms approved by the State-
(a) the State may Complete or arrange for the Completion of the Temporary
Casino Complex or the Melbourne Casino Complex or both at the cost of
the Company; and
(b) any moneys expended by the State in or in connection with Completing
or attempting to Complete the Temporary Casino Complex or the
Melbourne Casino Complex or both, and the amount of any loss, damages
or costs suffered or incurred by the Authority or the State as a
result of the termination of this document or any event giving rise to
the termination of this document, will be a debt due and payable by
the Company to the State and the Company indemnifies the State against
all those losses, damages or costs.
25.6. In the event that the State exercises its rights under clause 25.5 or
otherwise to Complete the Melbourne Casino Complex or the Temporary Casino
Complex or both, the State-
(a) will do so in all material respects in accordance with the Design and
Construction Programme, the Temporary Casino Complex Development
Proposal and the Melbourne Casino Complex Development Proposal but
subject to such variations as the State and the Financiers may agree;
and
(b) will be responsible as if the State were doing so as chargee under the
Fixed and Floating Charge.
25.7. Interest will be payable by the Company to the State on all moneys
expended by the State under clause 25.5 at the rate equal to the aggregate of
the Bill Rate and 2% per annum on the first Business Day of each month and
will accrue daily and be calculated monthly in arrears on the basis of the
actual number of days elapsed and a 365 day year and added to the amount owing
by the Company to the State and may be debited to any account of the Company
with the State and itself accrue interest in accordance with this clause.
25.8. All moneys payable by the Company to the State under clause 25.5 and all
interest payable under clause 25.7 must be paid by the Company to the State on
demand.
26. Continuity of interest of Company
26.1. If the Casino Licence is cancelled or if this document is terminated,
the provisions of clauses 26.2 to 26.8 will apply and shall continue to bind
the parties.
26.2. If the Casino Licence is cancelled after the date specified in clause
23.2(b), the Company shall not be entitled to a refund of the Licensing
Payment Amounts or any part of them.
26.3. If the Casino Licence is cancelled before the last date of the period
specified in clause 23.2(b) on grounds for disciplinary action-
(a) which are specified in paragraphs (a), (b) or (d) of the definition of
grounds for disciplinary action in section 20(1) of the
Casino Control Act; or
(b) (i) which are specified in paragraphs (c) or (e) of the definition of grounds for disciplinary action in section 20(1) of the Casino Control Act; and
(ii) the grounds arose, directly or indirectly, as a result of any act or
omission of the Company, or any director of the Company or any
Sponsor; the Company shall not be entitled to a refund of the
Licensing Payment Amounts or any part of them.
26.4. If the Casino Licence is cancelled before the last date of the period
specified in clause 23.2(b) on grounds other than those specified in clause
26.3, the State must refund the Licensing Payment Amounts to the Company as
follows-
(a) the refund must be made within 3 months after the cancellation of the
Casino Licence;
(b) the amount of the refund shall be that amount which bears the same
proportion to the amount of the Licensing Payment Amounts as the
unexpired portion as at the date of cancellation of the Casino Licence
of the period commencing on the Licensing Date and terminating on the
last day of the period specified in clause 23.2(b) bears to the whole
of that period.
26.5. If the Casino Licence is cancelled or surrendered at any time, and the
State determines that it wishes a licence to be granted to a person other than
the Company for the operation of a casino in the Melbourne Casino Complex, the
following provisions will apply-
(a) the State shall give a notice to the Company informing the Company
that the State requires the Company to grant to the new casino
operator a sub-lease of the Melbourne Casino and the Company must do
so in accordance with clauses 26.5(b) to (i) inclusive;
(b) the sub-lease will commence on the date of issue of the new licence
and end on the termination of the new licence or the termination of
the Site Lease, whichever is the earlier;
(c) the initial rental payable under the sub-lease will be the market
rental as at the date of commencement of the sub-lease of the
Melbourne Casino, as agreed between the State and the Company, and
will be payable monthly in advance on the first Business Day of each
month;
(d) the sub-lease rent will be reviewed annually to the market rental as
agreed between the sub-lessor and the sub-lessee, and failing
agreement, determined in accordance with clause 26.6 as if a notice
had been issued under this clause on the anniversary of the
commencement of the sub-lease;
(e) the sub-lessee will be liable to pay to the sub-lessor all outgoings
which are properly attributable to the occupation and use of the
Melbourne Casino;
(f) the sub-lease will contain all appropriate rights, including rights of
access and egress over the Melbourne Casino Complex to the Melbourne
Casino, as are necessary to enable the casino operator to operate a
casino in the Melbourne Casino Complex;
(g) the other terms and conditions of the sub-lease will be similar to the
terms and conditions of the Site Lease in so far as they relate to the
Melbourne Casino and to the extent that it is appropriate to include
them in the sub-lease;
(h) the form of the sub-lease shall be as determined by the State;
(i) the Company must use its best endeavours to facilitate the operation
of the Melbourne Casino within the Melbourne Casino Complex and this
obligation shall also be a term of the sub-lease.
26.6. If within 1 month after the service of the notice under clause 26.5 the
State and the Company have not agreed on the market rental to be payable under
the sub-lease, the market rental will be determined in accordance with the
following provisions-
(a) within 10 Business Days after the expiration of the period of 1 month
from the date of service of the notice, the State and the Company will
each appoint a valuer (each a "Representative Valuer") to act on its
behalf in relation to the determination of the market rental of the
Melbourne Casino;
(b) an independent valuer ("Independent Valuer") will be appointed-
(i) by agreement in writing by the Representative Valuers; or
(ii) failing such agreement within 20 Business Days after the appointment
of the Representative Valuers, then at the request of either
Representative Valuer by the President of the Victorian Division of
the Australian Institute of Valuers and Land Economists Inc;
(c) the Independent Valuer must as soon as practicable establish a
procedure by which submissions are to be made by each Representative
Valuer as to the market rental of the Melbourne Casino but so that all
submissions are made to the Independent Valuer within 20 Business Days
of his appointment;
(d) following completion of the period referred to in clause 26.6(c) the
Independent Valuer must consider the submissions made, seek further
submissions if required and, within 20 Business Days after the end of
the period referred to in clause 26.6(c) and having regard to the
matters referred to in clause 26.7, determine the market rental of the
Melbourne Casino;
(e) in determining the market rental of the Melbourne Casino the
Independent Valuer will be acting as an expert and not as an
arbitrator and his decision will be final and binding on the parties.
26.7. In determining the market rental of the Melbourne Casino under clause
26.6 the Independent Valuer must have regard to all matters to which the
valuer believes the valuer should have regard to in making such a
determination including but not restricted to casino facilities in Australia
and overseas, first class international hotels, major convention facilities
and other entertainment and tourist related facilities.
26.8. If following the expiration of the Casino Licence the State determines
that it wishes a licence to be granted to a person other than the Company for
the operation of a casino in the Melbourne Casino Complex, the provisions
contained in clauses 26.5 to 26.7 will apply with all necessary changes in
point of detail so as to confer a sub-lease on the new licensee.
PART 7-GENERAL
27. Warranties of the Company
27.1. The Company makes the Warranties to the State as at the date of this
document and for each day up to and including the Licensing Date.
27.2. Each Warranty shall be construed separately and the meaning of each
shall in no way be limited by reference to any other representation or
warranty contained in this document.
28. Company relies on own judgment
28.1. Save where a statement, representation or warranty is given in its
favour under this document or any Transaction Document, the Company
acknowledges that it is entering into this document and the other Transaction
Documents in reliance on its own judgment and following review of the Site and
the Temporary Casino Site and the business opportunity provided by, among
other things, the Casino Licence, and not in reliance on any conduct of or
statements, warranties or representations made to the Company or to any other
person by or on behalf of the State or any of its servants, agents or
consultants.
28.2. Save for any statement, representation or warranty made in its favour
under this document or any Transaction Document, the Company acknowledges and
agrees that no action lies against the State or any of its servants, agents or
consultants and that no compensation of any kind is payable to the Company in
relation to anything done or purported to be done or not done for the purposes
of the establishment or operation of the Temporary Casino, Temporary Casino
Complex, Melbourne Casino or Melbourne Casino Complex prior to the execution
of this document.
28.3. Nothing in this clause 28 limits any liability of Golder Associates Pty
Ltd to the Company.
29. Indemnity
29.1. The Company indemnifies and will keep indemnified the State and its
servants, agents and consultants in respect of all actions, claims, demands or
costs of third parties arising out of or in connection with any work carried
out by or on behalf of the Company pursuant to this document or relating to
the Company's operations (including but not limited to the operations of the
Temporary Casino Complex and the Melbourne Casino Complex) or arising out of
or in connection with the construction, financing, maintenance or use of the
Temporary Casino Complex or the Melbourne Casino Complex except expenses of
the Authority which are covered by the Casino Supervision and Control Charge.
29.2. The indemnity in clause 29.1 does not apply to the extent that any
actions, claims, demands or costs arise as a result of the negligence or
wilful default of the State.
29.3. The Casino Supervision and Control Charge reimburses the Authority for
expenses incurred in respect of-
(a) the supervision and monitoring by the Authority of the establishment
of the Temporary Casino and the Melbourne Casino; and
(b) the supervision of the Temporary Casino and the Melbourne Casino by
the Authority.
30. Confidentiality
30.1. All documents and information provided by one party to another party
under this document must be kept confidential and not disclosed to any person
without the consent of the other party unless-
(a) the information is in the public domain;
(b) disclosure is required by law;
(c) the disclosure is necessary for the purpose of obtaining any consent,
authorisation, approval or licence from any government or public body
or authority;
(d) it is necessary or desirable that the disclosure be made to any
taxation or fiscal authority;
(e) the disclosure is made on a confidential basis to the officers,
employees or agents of a party or to the professional advisers of a
party for the purposes of obtaining professional advice in relation to
any Transaction Document or the enforcement of any Transaction
Document or otherwise for the purpose of consulting those professional
advisers;
(f) the disclosure is made by the Company on a confidential basis to any
actual or prospective financier or agent of a financier to the
Company;
(g) the disclosure is necessary in relation to any procedure for discovery
of documents or any proceedings before any court, tribunal or
regulatory body; or
(h) the disclosure is necessary for the purposes of obtaining listing on
the Australian Stock Exchange.
30.2. The obligations in clause 30.1 shall apply after termination of this
document.
31. Day of payment If any day for the payment of money under this document
falls on a day which is not a Business Day, the payment will be due on the
next day which is a Business Day.
32. Notices
32.1. A notice or approval required or to be given under this document must
be-
(a) in writing;
(b) delivered by hand or served by prepaid post or facsimile to the
recipient at its address or facsimile number appearing in this clause
or such other address or facsimile number as the recipient may have
notified the other party-
(i) in the case of the State- The Secretary to the Department of Treasury
1 Treasury Place
MELBOURNE VIC 3000
Facsimile: (03) 651 6228 with a copy to the Authority- Chairman Victorian
Casino Control Authority Level 27, 459 Collins Street
MELBOURNE VIC 3000
Facsimile: (03) 621 1803
(ii) in the case of the Company- Lloyd J. Williams Chief Executive Officer
Crown Casino Ltd. 311 Glenferrie Road MALVERN VIC 3144 Facsimile: (03)
823 6105
32.2. A notice or approval given in accordance with clause 32.1 is taken to be
received-
(a) if hand delivered, on the day of delivery if delivered before 4.00
p.m. on a Business Day and otherwise on the Business Day next
following;
(b) if sent by prepaid post, 3 days after the date of posting; or
(c) if sent by facsimile, on the day on which the message confirmation is
received if received before 4.00 p.m. on a Business Day and otherwise
on the Business Day next following.
32.3. The provisions of clause 32 are in addition to any other mode of service
permitted by law.
32.4. A copy of each notice given under this document to the State must be
given to the Authority.
33. Costs and stamp duty
33.1. Each party must pay its own costs of preparing and executing this
document.
33.2. The Company must pay all stamp duty on this document and on any document
executed to give effect to this document.
34. No waiver A failure of a party at any time to require full or part
performance of any obligations under this document will not affect in any way
the rights of that party to require that performance subsequently.
35. Governing law
35.1. This document is governed by the laws applying in Victoria.
35.2. Each party irrevocably and unconditionally submits to the non-exclusive
jurisdiction of the courts of Victoria and courts entitled to hear appeals
from those courts.
36. Assignment
36.1. The Company must not without the prior written consent of the State-
(a) assign any of its rights under this document; or
(b) effect the assumption of any of its duties and obligations under this
document by any other person, other than pursuant to a Permitted
Encumbrance as defined in the Casino Agreement.
36.2. The State may assign, transfer or dispose of its rights under this
document or any other Transaction Document-
(a) to the Authority or to any agency of the government of the State or
statutory authority or corporation which has taken over the objects
and functions of the Authority under the Casino Control Act; or
(b) with the approval in writing of the Company to any person, such
approval not to be unreasonably withheld; provided that the assignee
enters into an agreement with the Company agreeing to be bound by the
provisions of this document and each other Transaction Document to
which the State is a party.
37. Further assurances Each party must do or cause to be done anything
necessary or desirable to give effect to this document, and will refrain from
doing anything which might prevent full effect being given to this document.
38. Counterparts
38.1. This document may be executed in any number of counterparts.
38.2. All counterparts taken together will be deemed to constitute the one
document.
39. Severability
39.1. The parties agree that a construction of this document which results in
all provisions being enforceable is to be preferred to a construction which
does not so result.
39.2. If, despite the application of clause 39.1, a provision of this document
is illegal or unenforceable-
(a) if the provision would not be illegal or unenforceable if a word or
words were omitted, that word or those words are severed; and
(b) in any other case, the whole provision is severed, and the remainder
of this document continues to have full force and effect.
39.3. Clause 39.2 does not apply where its application alters the basic nature
of this document or is contrary to public policy.
40. Interpretation
40.1. In this document, unless the context otherwise requires or the contrary
intention appears-
(a) the singular includes the plural and vice versa and words importing a
gender include other genders;
(b) terms importing natural persons include partnerships, bodies
corporate, associations, governments and governmental and local
authorities and agencies;
(c) a reference to any legislation, statutory instrument or regulation is
construed in accordance with the Acts Interpretation Act 1901
(Commonwealth) or the equivalent State legislation, as applicable, and
includes any re-enactment or amendment to that legislation, statutory
instrument or regulation;
(d) other grammatical forms of defined words or phrases have corresponding
meanings;
(e) a reference to a clause, paragraph, schedule or annexure is a
reference to a clause or paragraph of or schedule or annexure to this
document and a reference to this document includes any schedules and
annexures;
(f) where a party comprises two or more persons the provisions of this
document binding that party bind those persons jointly and severally;
(g) terms defined in the Corporations Law as at the date of this document
have the meanings given to them in the Corporations Law at that date;
(h) "party" means a party to this document;
(i) a reference to a party to this document or any other document or
agreement includes its successors and permitted assigns;
(j) a reference to a document or agreement, including this document,
includes a reference to that document or agreement as novated, altered
or replaced from time to time;
(k) a reference to "$A", "dollar", "AUD" or "$" is a reference to
Australian currency;
(l) a reference to writing includes typewriting, printing, lithography,
photography and any other method of representing or reproducing words,
figures or symbols in a permanent and visible form; and
(m) a reference to a specific time for the performance of an obligation is
a reference to that time in the State.
40.2. In this document headings are for ease of reference only and do not
affect the construction of this document.
41. General obligations
41.1. The Company must-
(a) maintain its corporate existence;
(b) comply with all laws applicable to the matters the subject of this
document from time to time in force including, without limitation, the
Gaming Machine Control Act, and all mandatory requirements of any
Public Authority;
(c) obtain and renew at the proper times and maintain all Authorisations
required-
(i) for the Company to perform its obligations under this document;
(ii) for the Company to perform its obligations under each Transaction
Document; and
(iii) to allow this document and each Transaction Document to be enforced
against it;
(d) obtain and renew at the proper times and maintain all licences and
other Authorisations required or advisable or relied on for or in
connection with the carrying on of the Company's business;
(e) comply with the terms and conditions of each Lease to which it is a
party where a failure to do so would have a material adverse effect on
the Casino Assets or the operation of the Temporary Casino or the
Melbourne Casino;
(f) comply with its payment obligations under any agreement for the
purchase of property where a failure to do so would have a material
adverse effect on the Casino Assets or the operation of the Temporary
Casino or the Melbourne Casino;
(g) protect the Casino Assets and at the Company's expense prosecute or
defend all legal proceedings that are, or the defence of which is,
necessary or advisable for the protection of the Casino Assets to the
extent appropriate in accordance with prudent business practice; and
(h) carry out all work reasonably and properly required by any Public
Authority in relation to the Casino Assets where a failure to do so
would have a material adverse effect on the Casino Assets or the
operation of the Melbourne Casino or the Temporary Casino.
41.2. The Company must not, without the prior consent in writing of the State-
(a) Deal with or Dispose of any of the Casino Assets other than by way of
maintenance, repair or replacement;
(b) Deal with or Dispose of any of the Casino Assets other than in the
ordinary course of the Company's business;
(c) execute, create or permit to subsist any Encumbrance over or affecting
the Casino Assets other than a Permitted Encumbrance;
(d) pull down, alter, extend or remove any building, improvement or
fixture forming part of the Casino Assets where to do so would
materially adversely affect the Casino Assets or the operation of the
Melbourne Casino or the Temporary Casino;
(e) take on or under a Lease, or acquire for consideration, any asset
other than in the ordinary course of the Company's business;
(f) declare or pay a dividend if a demand has been properly made on the
Company under this document or any Transaction Document and has not
been satisfied in full;
(g) do anything or allow anything to be done in derogation of the rights
of the State or any other party under any Transaction Document; except
to the extent permitted by clause 29 of the Casino Agreement.
__________________ SCHEDULES
[Index]
[Table]
[Search]
[Notes]
[Noteup]
[Previous]
[Next]
[Download]
[Help]